Terms & Conditions

These Terms and Conditions ("Terms") govern your use of the Baton Rouge Sod website (batonrougesod.com) and the purchase of products and services from Baton Rouge Sod. By using our website or placing an order, you agree to these Terms.

---

1. Acceptance of Terms

By accessing our website or purchasing sod from Baton Rouge Sod, you confirm that you have read, understood, and agree to be bound by these Terms. If you do not agree with any part of these Terms, please do not use our website or services.

2. Products and Services

Baton Rouge Sod sells fresh-cut sod by the pallet and by the piece. We offer four grass types: St. Augustine, Bermuda, Zoysia, and Centipede. Our services include:

• Sod delivery within approximately 50 miles of Baton Rouge, Louisiana
• Professional sod installation services
• Free estimates and lawn measurement assistance

Product availability varies by season and supplier inventory. We reserve the right to limit quantities or discontinue any product without notice.

3. Pricing and Payment

All prices listed on our website are subject to change without prior notice. Prices are quoted in U.S. dollars.

• Payment is due at the time of delivery unless other arrangements have been made in advance
• We accept cash, checks, and major credit cards
• Delivery fees are calculated based on distance from our location and order size
• Sales tax is applied in accordance with Louisiana state and local regulations

4. Ordering and Delivery

Orders are placed by calling 225-310-8080 during business hours. Please have the following information ready when you call:

• Grass type and quantity (number of pallets or square footage)
• Delivery address and preferred delivery date
• Site access details (gate codes, driveway width, delivery placement preferences)

Minimum order requirements may apply depending on delivery distance. The customer is responsible for site preparation before delivery, including clearing the area where sod will be placed.

Delivery times are estimates and not guarantees. Weather, supplier delays, or high-demand periods may affect scheduling.

5. Sod Quality and Inspection

We take pride in delivering fresh, healthy sod. However, sod is a live, perishable product. Natural variations in color, texture, and thickness are normal and expected.

• Inspect all sod upon delivery before the driver leaves
• Report any quality issues within 24 hours of delivery by calling 225-310-8080
• Take photographs of any damaged or defective sod for documentation

Once sod has been accepted at delivery and the delivery vehicle departs, the customer assumes responsibility for the product.

6. Installation Services

Professional installation is available as a separate service. Installation terms include:

• A separate installation agreement is required before work begins
• Weather delays may affect the installation schedule, and Baton Rouge Sod is not liable for delays caused by rain, extreme heat, or other weather events
• The customer must provide access to a working water source for post-installation watering
• Installation pricing is based on square footage, soil condition, and site accessibility

7. Limitation of Liability

Sod is a living product. Results depend on proper care, watering, soil conditions, sunlight, and ongoing maintenance after delivery. Baton Rouge Sod is not responsible for:

• Sod that dies or deteriorates due to improper watering, lack of care, or neglect after delivery
• Damage caused by pests, disease, pets, or foot traffic after installation
• Results that vary from expectations due to soil quality or environmental conditions

Our total liability for any claim arising from the sale or delivery of sod shall not exceed the purchase price of the product in question.

8. Website Use

The content on batonrougesod.com is provided for informational purposes only. While we strive for accuracy, we do not guarantee that all information on the website is complete, current, or error-free.

• You may not scrape, copy, or reproduce website content without written permission
• You may not use automated tools or bots to access or interact with the website
• We reserve the right to modify or remove any content at any time

9. Governing Law

These Terms are governed by and construed in accordance with the laws of the State of Louisiana. Any disputes arising from these Terms or your use of our services shall be resolved in the courts of East Baton Rouge Parish, Louisiana.